1. Introduction
Welcome to Coolman Innovations. By engaging with our services, you agree to comply with the following terms and conditions. These terms govern your use of our services and form a binding agreement between you and Coolman Innovations.
2. Acceptance of Terms
It is not necessary for any Client to have signed an acceptance of these terms and conditions for them to apply. If a Client accepts a quote, then the Client will be deemed to have satisfied themselves as to the terms applying and have accepted these terms and conditions in full.
Please read these terms and conditions carefully. Any purchase/payment of an advance fee or use of our services implies that you have read and accepted our terms and conditions.
By accessing and using this website, you agree to comply with these Terms & Conditions. If you do not agree, please discontinue use immediately.
3. Description of Services
Coolman Innovations provides AI-driven website development, app development, social media management, and related digital solutions. Any new features enhancing our services are also subject to these terms. We reserve the right to modify, suspend, or discontinue any service without prior notice due to non-cooperation, non-payment, or undue delays by the client.
4. Payment Terms
• All projects require a 50% upfront payment before work begins.
• An additional 30% payment is due at the development stage.
• The remaining 20% payment must be completed before project handover or final
deployment.
• Payments are accepted via bank transfer, UPI, or other agreed-upon methods.
• Failure to complete payments within the agreed timeline may result in project suspension or
termination.
5. No Refund Policy
All payments made to Coolman Innovations are non-refundable. Once a payment is made, it is considered final, and no refunds will be issued under any circumstances.
6. Client Responsibilities
• Clients must provide all necessary information, content, and approvals required for the completion of the project within the agreed timeframe.
• Clients must designate a single point of contact to facilitate communication and approvals.
• Any delays beyond three (3) weeks may lead to project cancellation, with no refunds on previous payments.
7. Revisions and Approvals
• Clients will have seven (7) days after project completion to request minor revisions.
• Any additional changes beyond the agreed scope may incur extra charges.
• Failure to communicate revision requests within the stipulated period will be considered as project acceptance.
8. Intellectual Property & Ownership
• Upon full payment, clients receive ownership of the final website or application.
• Coolman Innovations retains rights to any proprietary tools, templates, or technologies used in development.
• Source files (e.g., design files, code repositories) are not included unless explicitly agreed upon in writing.
• All content, research, and insights provided on this platform remain our intellectual property. Users may not reproduce, resell, or distribute our data without explicit permission.
9. Limitation of Liability
• Coolman Innovations shall not be held liable for any losses, damages, or delays arising from unforeseen circumstances, third-party failures, or client-side issues.
• Clients are responsible for testing and reviewing the final product before launch.
• We are not responsible for third-party service disruptions, hosting issues, or security breaches beyond our control.
10. Termination & Refund Policy
• Clients may cancel projects within three (3) days of signing the agreement for a partial refund.
• No refunds will be issued after this period, and all work completed must be paid for.
• Coolman Innovations reserves the right to terminate services if clients fail to meet their obligations, including payment delays or unresponsiveness.
11. Support & Maintenance
• A complimentary two-month support period is provided post-launch for minor updates.
• Any additional support, updates, or maintenance beyond this period is chargeable.
12. Confidentiality
• Coolman Innovations will maintain confidentiality regarding client projects and sensitive
data.
• Clients agree not to disclose any proprietary tools, pricing, or methodologies used by
Coolman Innovations.
13. Dispute Resolution
• Any disputes shall be resolved amicably through negotiation.
• If unresolved, disputes will be subject to the jurisdiction of Bangalore, India.
14. Modifications to Terms
Coolman Innovations reserves the right to modify these terms and conditions at any time. Any
changes will be communicated to clients as necessary
15. Nature of Services
We provide business intelligence and market insights sourced from publicly available data, user-submitted information, and legally permissible sources. We do not engage in hacking, unauthorized access, or illegal data collection.
16. Governing Law
These terms and conditions shall be governed by and interpreted in accordance with the laws of
India. Any disputes shall be resolved in the courts of Bangalore, India.
17. Compliance with Laws
Users are responsible for ensuring that their use of our services complies with all applicable local, national, and international laws. We do not encourage or support unethical or illegal data use.
18. No Liability for Misuse
We are not responsible for how users interpret or utilize the information provided. Any misuse of data by third parties is beyond our control, and we disclaim all liability arising from such actions.
18. Data Accuracy & Availability
All information is provided “as is” without warranties of accuracy, completeness, or reliability. We do not guarantee uninterrupted or error-free access to our services.
19. No Affiliation with Competitors
We are not affiliated with, endorsed by, or in partnership with any of the companies mentioned in our reports or databases. Any resemblance to actual company data is purely coincidental.
20. Indemnification
You agree to indemnify and hold us harmless from any claims, damages, or legal actions arising from your use or misuse of our services.
21. Amendments
We reserve the right to modify these Terms & Conditions at any time without prior notice. Continued use of our services constitutes acceptance of the revised terms.
22. Jurisdiction
Any disputes arising from these terms shall be governed by the laws of Bangalore Jurisdiction, and legal proceedings shall take place in Bangalore High Court.
23. Contact Information
For any queries regarding these terms, please contact Coolman Innovations.
Email: info@coolmaninnovations.com
